C.R.S. Section 13-20-803
List of defects required

(1)

In addition to the notice of claim required by section 13-20-803.5, in every action brought against a construction professional, the claimant shall file with the court or arbitrator and serve on the construction professional an initial list of construction defects in accordance with this section.

(2)

The initial list of construction defects shall contain a description of the construction that the claimant alleges to be defective. The initial list of construction defects shall be filed with the court and served on the defendant within sixty days after the commencement of the action or within such longer period as the court in its discretion may allow.

(3)

The initial list of construction defects may be amended by the claimant to identify additional construction defects as they become known to the claimant. In no event shall the court allow the case to be set for trial before the initial list of construction defects is filed and served.

(4)

If a subcontractor or supplier is added as a party to an action under this section, the claimant making the claim against such subcontractor or supplier shall file with the court and serve on the defendant an initial list of construction defects in accordance with this section within sixty days after service of the complaint against the subcontractor or supplier or within such longer period as the court in its discretion may allow. In no event shall the filing of a defect list under this subsection (4) delay the setting of the trial.

Source: Section 13-20-803 — List of defects required, https://leg.­colorado.­gov/sites/default/files/images/olls/crs2023-title-13.­pdf (accessed Oct. 20, 2023).

13‑20‑101
What actions survive 13‑20‑102
Effect of repeal 13‑20‑201
Legislative declaration 13‑20‑202
Civil causes abolished 13‑20‑203
Breach of contract to marry not actionable 13‑20‑204
Certain contracts made in settlement of claims void 13‑20‑205
Unlawful to file pleading 13‑20‑206
Unlawful to name corespondent 13‑20‑207
Corespondent not to be disclosed - cross-examination - effect 13‑20‑208
Penalty for violations 13‑20‑401
Definitions 13‑20‑402
Physician to provide information for written informed consent 13‑20‑403
Restrictions on electroconvulsive treatment - rights of minors 13‑20‑601
Legislative declaration 13‑20‑602
Actions against licensed professionals and acupuncturists - certificate of review required 13‑20‑701
Legislative declaration 13‑20‑702
Definitions 13‑20‑703
Environmental third-party liability - ownership 13‑20‑801
Short title 13‑20‑802
Legislative declaration 13‑20‑802.5
Definitions 13‑20‑803
List of defects required 13‑20‑803.5
Notice of claim process 13‑20‑804
Restriction on construction defect negligence claims 13‑20‑805
Tolling of statutes of limitation 13‑20‑806
Limitation of damages 13‑20‑807
Express warranty - not affected 13‑20‑808
Insurance policies issued to construction professionals 13‑20‑901
Class actions - appellate review 13‑20‑1001
Short title 13‑20‑1002
Legislative declaration 13‑20‑1003
Definitions 13‑20‑1004
Forum non conveniens 13‑20‑1101
Action involving exercise of constitutional rights - motion to dismiss - appeal - legislative declaration - definitions 13‑20‑1201
Definitions 13‑20‑1202
Civil cause of action for sexual misconduct against a minor - exceptions 13‑20‑1203
Limitation on action - retroactive application 13‑20‑1204
Waiver of liability void 13‑20‑1205
No contributory negligence - interest on damages - limitation on damages 13‑20‑1206
Attorney fees 13‑20‑1207
Applicability of part to public entities and public employees - damages - no duty to indemnify
Green check means up to date. Up to date

Current through Fall 2024

§ 13-20-803’s source at colorado​.gov